contracting with the State to do the Contract Work. The Contractor is one of the Parties to this Agreement. or means one or more of the fifty-eight (58) superior Court(s)” “Court(s)” “Trial courts in the California state court system. trial all types of raw data, articles, papers, charts, records, reports, studies, “Data” research, memoranda, computation sheets, questionnaires, surveys, and other documentation. means calendar day, unless otherwise specified. “Day” or means one or more items, if specified in the “Deliverable(s)” “Submittal(s)” Contract Documents, that the Contractor shall complete and deliver or submit to the State for acceptance. Majeure” means a delay which impacts the timely performance of Work for “Force which neither the Contractor nor the State are liable because such delay or failure to perform was unforeseeable and beyond the control of the Party. Acts of Force Majeure include, but are not limited to: Acts of God or the public enemy; Acts or omissions of any government entity; Fire or other casualty for which a Party is not responsible; Quarantine or epidemic; Strike or defensive lockout; and, Unusually severe weather conditions. Branch Entity” or the Judicial Council of California, the “Judicial “JBE” Administrative Office of the Courts, any of the California Appellate Courts (which includes the Supreme Court of California and the California Courts of Appeal), any of the Courts, the Habeas Corpus Resource Center and the Commission on Judicial Performance of the State of California (collectively referred to as Judicial Branch Entities). Personnel” means the Contractor’s personnel named in Exhibit E, “Key Contractor’s Key Personnel, whom the State has identified and approved to perform the Work of the Contract. Roles of Key Personnel are set forth in Exhibit E, Contractor’s Key Personnel. means all types of tangible personal property, including but not limited to “Material” goods, supplies, equipment, commodities, and information and telecommunication technology.
contracting with the State to do the Contract Work. The Contractor is one of the Parties to this Agreement. “Court(s)” or “Trial Court(s)” means one or more of the fifty-eight (58) superior courts in the California state court system. “Data” all types of raw data, articles, papers, charts, records, reports, studies, research, memoranda, computation sheets, questionnaires, surveys, and other documentation. “Day” means calendar day, unless otherwise specified. “Deliverable(s)” or “Submittal(s)” means one or more items, if specified in the Contract Documents, that the Contractor shall complete and deliver or submit to the State for acceptance. “Force Majeure” means a delay which impacts the timely performance of Work for which neither the Contractor nor the State are liable because such delay or failure to perform was unforeseeable and beyond the control of the Party. Acts of Force Majeure include, but are not limited to: Acts of God or the public enemy; Acts or omissions of any government entity; Fire or other casualty for which a Party is not responsible; Quarantine or epidemic; Strike or defensive lockout; and, Unusually severe weather conditions. “Judicial Branch Entity” or “JBE” the Judicial Council of California, the Administrative Office of the Courts, any of the California Appellate Courts (which includes the Supreme Court of California and the California Courts of Appeal), any of the Courts, the Habeas Corpus Resource Center and the Commission on Judicial Performance of the State of California (collectively referred to as Judicial Branch Entities). “Key Personnel” means the Contractor’s personnel named in Exhibit E, Contractor’s Key Personnel, whom the State has identified and approved to perform the Work of the Contract. Roles of Key Personnel are set forth in Exhibit E, Contractor’s Key Personnel. “Material” means all types of tangible personal property, including but not limited to goods, supplies, equipment, commodities, and information and telecommunication technology. trial
Attachment-B-Terms-and-Conditions.docx