(End of Clause) [END OF SECTION] SECTION E - INSPECTION AND ACCEPTANCE E.1 52.246-12 INSPECTION OF CONSTRUCTION (APR 1996) (a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components. (b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract. (c) Government inspections and tests are for the sole benefit of the Government and do not - (1) Relieve the Contractor of responsibility for providing adequate quality control measures; (2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance; (3) Constitute or imply acceptance; or (4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section. (d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization. (e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract. (f) The Contractor without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.
(End of Clause) [END OF SECTION] SECTION E - INSPECTION AND ACCEPTANCE E.1 52.246-12 INSPECTION OF CONSTRUCTION (APR 1996) (a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components. (b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract. (c) Government inspections and tests are for the sole benefit of the Government and do not - (1) Relieve the Contractor of responsibility for providing adequate quality control measures; (2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance; (3) Constitute or imply acceptance; or (4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section. (d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization. (e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract. (f) The Contractor without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.